HomeMy WebLinkAbout2001.08.21_OPWA AgendaPUBLIC NOTICE OF THE MEETING OF THE
OWASSO PUBLIC WORKS AUTHORITY
TYPE OF MEETING: Regular
DATE: August 21, 2001
TIME: 6:30 p.m.
PLACE: Council Chambers, Owasso Community Center
Notice and agenda filed in the office of the City Clerk and posted at City Hall at 4:00 p.m. on
Friday, August 17, 2001.
Marci Boutwell, Autho ity Secretary
y
L Call to Order
Chairman Barnhouse
2. Invocation
Jim McElrath, Support Services Director
3. Flag Salute
4. Roll Call
S. Consideration and Appropriate Action Relating to a Request for Approval of the Consent
Agenda. All matters listed under "Consent" are considered by the Trustees to be routine
and will be enacted by one motion. Any Trustee may, however, remove an item from
consent by request. A motion to adopt the Consent Agenda is non-debatable.
Owasso Public Works Authority
August 21, 2001
Page 2
A. Approval of the Minutes of August 7, 2001 Regular Meeting,
Attachment 9-5-A
B, Approval of Claims.
Attachment 45-B
6. Consideration and Appropriate Action Relating to OPWA Resolution #2001-09, a
Resolution Establishing Sanitary Sewer Rates and Refuse Rates for Rural Water Customers
Residing Within the Corporate Limits of the City of Owasso.
Ms Bishop
Attachment #6
The staff will recommend Trustee approval of OPWA Resolution #2001-09,
7. Consideration and Appropriate Action Relating to an Amendment to a Revenue
Anticipation Note Between the City of Owasso and the Owasso Public Works Authority,
Ms Bishop
Attachment #7
The staff will recommend approval of an amendment to the Revenue Anticipation Note
dated August 4, 1998, and authorization of the payment of accrued interest in the amount of
$70,060.41
Owasso Public Works Authority
August 21, 2001
Page 3
& Consideration and Appropriate Action Relating to Change Order # #1, a Change Order to a
Contract Between the Owasso Public Works Authority and Sapulpa Digging Inc for the
Construction of the Ator Relief Line,
Mir bates
Attachment #8
I
The staff will recommend trustee approval of Change Order ##1, adding 81 days to the
project time, extending the completion date to November 14, 2001.
Consideration and Appropriate Action Relating to a Report from the Yardwaste
Committee.
Mr Roberts
.Attachment 119
The staff will present the findings of the Yardwaste Committee and recommend 'Trustee
approval of the action plan as submitted.
10. Report from OPWA Tanager,
11. Report from OPWA Attorney.
Owasso Public Works Authority
August 21, 2001
Page 4
12, New Business.
13, Adjournment.
PUBLIC NOTICE OF THE MEETING OF THE
OWASSO CITY COUNCIL,
TYPE OF MEETING: regular
DATE: August 21, 2001
'TIME: 6:30 p.m.
PLACE: Council Chambers, Owasso Community Center
Notice of Addendum filed in the office of the City Clerk and posted at city hall at 10:00 a.m. on
Monday, August 20, 2001.
Marcia outwell, City C12rk
ADDENDUM TO AGENDA
The following is submitted as an addendum to the Agenda filed on August 17, 2001, and amends
the recommendation on Item #12 as follows:
12. Consideration and Appropriate Action relating to the Award of a Bid for the Purchase and
Installation of Window Treatments for the New City Hall /Police Station.
Mr Rooney
Attachment #12
The staff has completed the bidding process and will recommend that the bid for the
purchase and installation of window treatments for the new City Hall /Police Station be
awarded to Kimball's Ace Hardware, Owasso, OK in the amount of $6220.
OWASSO PUBLIC WORKS AUTHORITY
MINUTES OF REGULAR MEETING
Tuesday, August 7, 2001
The Owasso Public Works Authority met in regular session on Tuesday, August 7, 2001 in the
Council Chambers at the Owasso Community Center per the Notice of Public Meeting and
Agenda posted on the City Hall bulletin board at 4:00 p.m. on Friday, August 3, 2001.
ITEM 1: CALL TO ORDER
Chairman Barnhouse called the meeting to order at 7:05 p.m.
ITEM 2: FLAG SALUTE
The flag salute was held during the City Council meeting preceding this meeting.
ITEM 4: ROLL CALL
STAFF
Larry Mitchell, City Manager
Ronald D Cates, Authority Attorney
Marcia Boutwell, Authority Secretary
A quorum was declared present.
The consent agenda included minutes of the July 17, 2001 regular meeting, by reference made a
part hereto. Item B on the consent agenda included the following claims: (1) Owasso Public
Works Authority $194,506.85; (2) OPWA Capital Improvements $77,936.31; (3) OPWA Sales
Tax $111,498.65; (4) Payroll #1 $39,900.43; (5) #2 Payroll $40,448.61. Ms Armstrong moved,
seconded by Mr Brogdon, to approve the consent agenda. Item C on the consent agenda
requested d approval and acceptance of the OWRI3 Letter of Binding Commitment to Make a
Clean Water State Revolving Fund loan, and authorization for the Chairman and Secretary to
execute the document.
Owasso Public Works Authority
AYE: Armstrong, Brogdon, Helm, Williams, Barnhouse
NAY: None
Motion carried 5-0.
ITEM 5: REPORT FROM OPWA MANAGER
No report.
ITEM 6: RE PORT FROM OP WA ATTORNEY,
No report.
ITEM 7: NEW BUSINESS.
None.
ITEM 8: ADJOURNMENT
Mr Brogdon moved, seconded by Mr Williams to adjourn.
AYE: Brogdon, Williams, Helm, Armstrong, Barnhouse
NAY: None
Motion carried 5-0, and the meeting was adjourned at 7:08 p.m.
Marcia Boutwell, Authority Secretary
-2-
August 7, 2001
Mary Lou Barnhouse, Chair
Fund
owl
General
105 Municipal Court
634.47
110 Managerial
1,485.36
150 General Government
11,012.04
160 Community Development
4,992.64
170 Engineering
38181
175 Information Systems
203.95
181 Support Services
4,675.68
201 Police Services
9,735.58
215 Police Communications
153.68
221 Animal Control
1,494.74
250 Fire Services
130,059.10
280 Emergency Preparedness
90.32
300 Streets
10,903.81
515 Park Maintenance
3,184.41
550 Community Center
3,075.34
710 Economic Development
49.50
TOTAL
182,134.43
Ambulance
255 Ambulance
1,498.97
TOTAL
1,498.97
Ambulance Capital
255 Ambulance
7,143.15
TOTAL
7,143.15
Capital Improvements
Computerization
4,100.00
TOTAL
4,100.00
Bond Projects
City Hall/Police Station
118,075.22
TOTAL
118,075.22
OPGA
Merchandise
2,852.98
Food and Beverage
670.50
605 Cart Operations
70.62
610 Golf Course Maintenance
5,044.00
690 Golf Administration
3,732.42
800 Debt Service
38,934.43
TOTAL
51,304.95
OPWA Capital Improvements
OPWA Sales Tax
City Garage
450 Wastewater Treatment Plant
455 Wastewater Collections
Debt Service
TOTAL
Debt Service
TOTAL
185 City Garage
TOTAL
101.51
2,973.19
4,348.71
19,821.72
16,023.55
5,378.99
10,273.52
2,353.40
61,274M
104,867M
51,253.26
156,120.35
111,498.65
111,498.65
9,329.42
9,329.42
Worker s'Comp Self Insurance 150 Workers" Corp 4,414.41
TOTAL 4,414.41
Claims Total 706=,894. 14
PAY PERIOD ENDING DATE 08/11/01
DEPARTMENT
OVERTIME TOTAL
EXPENSES EXPENSES
0.00 2,216.90
77'astewater 535.38 5,050. 3 1 7
. . . . . . . . . . . . . . . . .
Film,
Nymmm
TO: HONORABLE CHAIR AND TRUSTEES
OWASSO PUBLIC WORKS AUTHORITY
FROM: SHERRY BISHOP
FINANCE DIRECTOR
SUBJECT. RE SOLUTION NUMBER 2001-09
RATES FOR CITY UTILITIES IN RURAL WATER DISTRICTS
DATE- August 16, 2001
BACKGROUND:
Staff recommends OPWA Trustee approval of Resolution No.2001-09 establishing utility rates for
rural water district customers residing inside the corporate limits of the City of Owasso.
Resolution No.2001-09
TWITIRM-WO M-700579107,43
OWASSO, OKLAHOMA
RESOLUTION NO. 2001-09
A RESOLUTION OF THE TRUSTEES OF THE OWASSO PUBLIC
WORKS AUTHORITY ESTABLISHING SANI'T'ARY SEWER AND
FUSE RATES FOR RURAL WATER DISTRICT CUSTOMERS
SIDING WITHIN THE CORPORATE LIMITS OF THE CITY OF
OWASSO, OKLAHOMA.
BE IT RESOLVED BY THY, TRUSTEES OF THE OWASSO PUBLIC WORKS
AUTHORITY THAT the following rates be, and the same hereby are, established as sanitary
sewer and refuse rates for rural water district customers residing within the corporate limits of
the City of Owasso, Oklahoma, utilizing the sanitary sewer service of the Owasso Public Works
.Authority, Owasso, Oklahoma.
Residential-
Residential customers of the Owasso Public Works Authority shall be charged the then
applicable rate as established, or thereafter increased, by the 'Trustees of the Owasso Public
Works Authority for all residential sanitary sewer service customers and residential refuse
service customers, regardless of whether or not said customers are water service customers,
residing within the City of Owasso, Oklahoma, assuming a 7200 gallon per month usage plus an
amount of 10% thereof as and for an administrative fee to the Rural Water District.
Commercial customers of the Owasso Public Works Authority shall be charged the then
applicable rate as established, or thereafter increased, by the Trustees of the Owasso Public
Works .Authority for all commercial sanitary sewer service customers and commercial refuse
customers, if applicable, regardless of whether or not said customers are water service customers,
residing within the City of Owasso, Oklahoma, assuming an assigned average usage plus an
amount of 10% thereof as and for an administrative fee to the Rural Water District.
DROVED this 215e day of August, 2001 by the Trustees of the Owasso Public Works
Authority.
Mary Lou Bamhouse, Chairperson
Marcia Boutwell, Authority Secretary
Ronald D Cates, Authority Attorney
MEMORANDUM
T HONORABLE CHAIR AND TRUSTEES
OWASS O PUBLIC WORKS AUTHORITY
FROM- SHERRY BISHOP
FINANCE DIRECTOR
SUBJECT. AMENDED REVENUE ANTICIPATION NOTE
DATE: August 16, 2001
BACKGROUND:
In March of 1998, the OP WA Trustees approved a concept plan for the construction and funding
of the Elm Creek Sewer Interceptor project. The concept allowed the interceptor to be constructed
with city-backed financing supported by a private sector "pay-back" as the property develops.
Financing for the project consisted of a bank note and a revenue anticipation note. The note with
First Bank of Owasso is a five-year, 5 % note for $1,200,000 dated December 1998. Monthly
payments are $23,000 with the final payment due in December of 2003.
The proposed amended Revenue Anticipation Note for $712,970.39 would pay 4% interest semi-
annually in February and August until maturity. Semi-annual principal payments would begin in
February of 2004 and continue through August of 2008. The RAN may be paid off at any time
should funds become available.
Staff recommends that OP WA Trustees authorize payment of accrued interest of $70,060.42 and
approve the Amended Revenue Anticipation Note.
ATTACHMENTS:
Amended Revenue Anticipation Note of the OP A, dated August 4, 2001
Revenue Anticipation Note of the OPWA, dated August 4, 1998
Loan Agreement
AMENDED REVENUE ANTICIPATION NOTE
OF
THE OWASSO PUBLIC WORKS AUTHORITY
Dated as of the 4"' day of August, a
Owasso, Tulsa County, Oklahoma $712,970.39
The Borrower may prepay this Note, in whole or in part, at any time prior to the due date hereof,
without penalty, If any payment shall be due on a Saturday or Sunday or upon any banking holiday
of the holder hereof, such payment shall be due and payable on the next succeeding banking day and
interest shall accrue to such day.
The City may, at any time prior to the due date of payment of this Revenue Anticipation Note call for
an early pre-payment in whole, or in pail, if it is determined by the City, in its sole discretion, that the
funds heretofore advanced pursuant to this Revenue Anticipation Note are needed by the City for its
operations, governmental or proprietary, and the Borrower is afforded a reasonable opportunity to
obtain reasonably satisfactory refinancing hereof
All parties (makers, sureties, guarantors and all others now or hereafter liable for payment of all or
any portion of the indebtedness evidenced by the Revenue Anticipation Note) severally waive
demand, presentment, notice of dishonor, protest, notice of protest, and diligence in collecting this
Revenue Anticipation Note and diligence in bringing and prosecuting suit against any party bound
hereby, and agree that no extension, renewal or partial payment, or release or substitution of collateral
before or after maturity, with or without notice, shall release or discharge the obligation of any party.
Upon the failure to pay when duo the principal and or interest, the holder hereof shall be entitled, at
its option, to extend the term or declare the unpaid principal balance of this Revenue Anticipation
Dote to be immediately due and payable. A failure by such holder to exercise such option will not
constitute a waiver of the right to exercise the same in the event of any subsequent default. After
maturity (whether by extension, acceleration or otherwise), interest shall accrue hereon at a rate of
interest often percent (10 %) per annum, If this Revenue Anticipation Tote is placed with an attorney
for collection upon any default, or to defend or enforce any rights of the holder(s) hereunder or any
instrument securing payment of this Revenue Anticipation mote, or if this Revenue Anticipation Note
is collected through barda -uptcy or other judicial proceeding, the Borrower agrees to pay the
reasonable attorney fees of the holder(s) of this Revenue Anticipation Dote and all reasonable costs
and expenses incurred in connection therewith.
This revenue Anticipation mote together with all extensions, renewals, substitutes, modifications
and /or changes in form hereof is secured by the Security Agreement which respects certain property
and interests located in Tulsa County, Oklahoma.
OWASSO PUBLIC WORKS AUTHORITY
an Oklahoma Public Trust
E
Mary Lou Earnhouse, Chairman
ATTEST:
Marcia Boutwell, Secretary
Delivery receipted this day of 52001.
M
ATTEST:
Marcia Boutwell, City Clerk
Mary Lou Earnhouse, Mayor
Exhibit B
REVENUE ANTICIPATION NOTE
OF
OWASSO PUBLIC WORKS AUTHORITY
PAYMENTSCFIE[JULE
Payment
Principal
|nt*nasd
Interest
Total
Date
pay—mmh$
Rate,
Eay-ffla��
2/4/02
4.0%
14.259.41
14.250.41
8/4/02
4.0%
14.250.41
14.259.41
2/4/03
4.0Y6
14,25941
14.259.41
8N/03
4.096
14.25041
14,258.41
2/4/04
48.000.00
4.0Y6
14.259.41
62.259.41
8/4/04
68.000.00
4.09&
13.299.41
01'299.41
2/4/85
70.000.00
4.096
11.839.41
81,03941
8/4/05
71.000.00
4.094
10.539.41
81.539.41
2/4/06
72.000.00
4.0%
9.119.41
81,119.41
8/4/06
74.000.00
4.0Y6
7.679.41
81,670.41
2/4/07
75.000.00
4.0%
6.19041
81.19941
8/4/07
77.000.00
4.09&
4.099.41
81.009.41
2/4/08
78.000.00
4.0%
3.159.41
81,15941
8/4/08
79,97839
4.096
1,599.41
81.569.80
M
REYEN )!_&H_ZMFAT__1D_N_NQTE
Q E
NRLI-Q W RKS A THORI:TX
_QK&fiSQ__p
Dated as of the 4th day of August, 1.998
Owasso, Tulsa County, Oklahoma $1,800,000.00
The Borrower may prepay this Note, in whole or in -part, at any time
prior to the due date hereof® without penalty® If any payment
shall be due on a Saturday or Sunday or up ®n any banking holiday of
the holder hereof, such payment shall be due and payable on the
next succeeding banking day and interest shall accrue to such daV.
The City may, at any tine prior to the due date of pavment of this
Revenue Anticipation Note call for an early pre-payment in whole,
or in part, if it is determined by the City, in it I s sole
discretion, that the funds heretofore advanced pursuant to this
By Ok&
Denise Bode,
Chairmal
IN
Mar *a ou
twelI® Secretary
Dell-v x-y receipted this � day of ,� 1998.
CITY OF OWASSO, OKLAHOMA
Byy�
Denise Bode, Mayor
ATTEST:
TO CITY OF OWASSO, OKLAHOMA
RESOLUTION NUMBER 2
LOAN AGREEMENT
°TMS LOANT ACS EMENT (the "Agreement ") made and entered into as of the 4th day of
August, 1998 by and among the Owasso public Works Authority, an Oklahoma public trust, (the
"Authority ") and the City of Owasso, Oklahoma, an Oklahoma Municipal Corporation (the "City").
WITNE, SSE 1-T:
WHEREAS, the City has determined to make a loan to the Authority, aggregating
$1,800,000.00 to be evidenced by the Authority's Revenue Anticipation Note payable to the order
of the City in the original principal amount not to exceed $1,800,000.00, (the "mote ") to eatable the
Authority, pursuant to certain of its approvals, to finance costs of the construction of the Elm Creek
Seger Interceptor Project (the "Project ").
WHEREAS, pursuant to the term and conditions hereinafter set forth, the City is willing to
make such loan to be evidenced by the Note-, and
VVHEREAS, the payment of the Note is to be secured by a subordinate security interest in the
revenues of the Authority, receipts and receivables, cinder the conditions as set forth hereinafter.
NOW, TIVEREFORE, in consideration of the mutual agreements herein made and other good
and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties
agree as follows:
1.1 The C 's Commitment. The City agrees, subject to the terms and conditions of
this Agreement, to make the loan to the Authority in the amount not to exceed $1,800,000.00.
1.3 Loan Advances. The loan advances on the Note shall be made pursuant to a
Loan Schedule to be executed after final approval of the construction contracts for the Project. Each
request for an advance shall be accompanied by a certificate signed by the project manager, describing
the invoices for which the loan advances are sought, certifying that the work, labor or materials for
which the loan advance is sought have been performed according to the plans and specifications or
as approved by the City, and certifying that sufficient funds are available under the Note to complete
the construction of the Project in accordance v✓ith the plans and specifications. Lien waivers from
all contractors and subcontractors shall be provided by the Authority with each loam advance.
1.4 `ferms_oi Lhe Tjo e. The Note shall be in substantially the form set forth in 21ibit
A attached hereto.
Interest shall accrue, be payable and subject to adjustment, as provided for in the Note on the
outstanding and unpaid principal balance thereon fioYn the date of first advance thereon until payment
in full thereof as set forth and provided therein.
2.1 Conditions. The obligations of the City to make the loan pursuant to this
Agreement are subject to there being no went of Default hereunder or an event which with notice
or lapse of time would become an Event of Default hereunder and the City having received in form
and substance satisfactory to it:
(a) A duly certified copy of the resolutions of the Authority authorizing execution and
delivery of this Agreement, and related instrtirnents, and the issuance, execution and
delivery of the Note;
(b) Original duly executed counterparts of (1) this Agreement, (ii) such financing
statement(s) as respect the foregoing,
(c) Such certificates, documents and certificates respecting the Authority, as City counsel
shall reasonably require;
(d) Such opinions of counsel for the Authority, as City counsel shall reasonably require;
(e) A detailed description and cost breakdown analysis of the Project (the `Breakdown ")
and all amendments thereto, all for approval by City;
N
(f) Such other and further inaterials and/or information as the City may reasonably
request; and
AARTIC L III
-E�
LA L M
Q B ! tL SE, ELD &—SAIMI ACTIQU
QA—
ION-
The Authority hereby agrees with the City that, so long as the Note remains outstanding:
4,1 PerfQrrnance of AqLeernent I
q. The Authority shall take all action and do all things
which it is authorized by law to take and do in order to perform and observe all covenants and
agreements on its part to be performed and observed under this Agreement and the Note and in order
to provide for and to assure payment of the principal of the Note and interest thereon when due.
4.2 Creation of Charges nn Revenues. The Authority shall not create or suffer to exist
any additional assignment, pledge, security interest or other lien, encumbrance or charge on any
revenues of the Authority to be pledged.
43 AMendmeq. The Authority shall not alter, amend or repeal the resolutions described
in Section 2.1(a) hereof, or, without the prior written consent of the City, agree to any alteration or
amendment of any of the instruments described in Sections 2.1(b) and 2.1(c) hereof, or take any
action impairing any authority, right or benefit given or conferred by such resolution or instruments.
4A. 1 cwt. The authority shall pay or cause to be paid the principal of and the
interest on the Note as the same becomes due, whether by acceleration or otherwise, but solely from
the sources referred to in Article fff hereof
4.5 egreventations and arrantie fAuthority. The Authority represents and
warrants to the City as follows: '
(a) The Authority is an Oklahoma public trust duly organized, validly existing and
in goad standing under the laws of the State of Oklahoma and all other states in which it is
necessary that the Authority be qualified to do business.
(b) The Authority and the Owasso City Council have taken all necessary actions
to authorize entering into this Agreement and to authorize the execution and delivery of the
Note, and the other documents contemplated hereby.
(c) The execution and delivery of this Agreement and, the Tote, will not cause,
constitute or result in a breach of any agreement, contract or other undertaking to which the
Authority is a party.
(d) The Authority shall deliver to the City copies, certified by the authority's
Secretary, of all resolutions and actions undertaken by the Authority or the Owasso City
Council to authorize this transaction.
(e) The Authority shall maintain its existence in Oklahoma.
(f) The Authority shall deliver to the City, within one week after they are
prepared, copies of the authority's quarterly financial statements.
4
5.1 Events of Default. Any one or more of the following shall constitute and
"Event of Default" hereunder;
(c) The entry against the Authority or Lessee of (1) any judgment in an amount of
$25,000 or more on a claim not covered by insurance which is not discharged
within thirty (.33 0) days of such judgement becoming a final judgment, or
(d) If the .Authority shall (1) apply for or consent to the appointment of a received, a
trustee or liquidator of themselves or itself, or of ail or a substantial part of its
assets, or (ii) file a petition or answer seeking reorganization or admit (by answer,
default or otherwise) the material allegations of a petition filed against them in any
reorganization proceeding; or
(e) If the Authority shall (1) become insolvent, generally fail to pay, or admit in writing
their respective inability to pay their respective debts as the fall due, (ii) snake a
general assignment for the benefit of their or its respective creditors, (iii) be
adjudicated a bankrupt or insolvent, or (iv) file a voiuntary petition in bankruptcy
or file a petition or answer seeking an arrangement with creditors or to take
advantage of any insolvency laws or admit (by answer, default or otherwise) the
material allegations of a petition filed against any of them in any bankruptcy,
arrangement or insolvency proceeding, or take or omit to take any action for the
purpose or with the result of effecting any of the foregoing; or
(g) 'Failure of the security interests granted in the Agreement to constitute a duly
perfected, valid security interest in the Revenues-, or
(h) The breach of, or default Under, any covenant, agreement, terra, condition,
provision, representation or warran' ®y contained in this Agreement, the Note, not
specifically referred to in this Section, if such breach or default is not cured within
thirty ( 0) days of the occurrence thereof, or
(i) In any event of default shall occur and shall continue for more than the period of
grace, if any, provided with respect thereto, render this Agreement; or
{)
The Project cannot be completed in accordance with the playas and specifications
approved by the City with the hinds remaining to be advanced on the Note.
52 R
ernedie�tL Default. Whenever any Event of Default referred to in Section 5.1
hereof shall have - occurred, the City may take any one or more of the following remedial steps:
(a) Declare all amounts payable hereunder and pursuant to the dote or any renewal
thereof, to be immediately due and payable without notice of default, presentment
or demand for payment, protest or notice of nonpayment or dishonor, or ether
notices or demands of any kind whatsoever, whereupon the same, together with
the accrued interest thereon, shall become immediately due and payable; or
(b) Realize upon its rights under the security agreement and such other collateral
documentation as may front time to time inure to the benefit: of the City, or
(c) `fare whatever action at lava or in equity may appear necessary or desirable to
collect the amount then due and thereafter to become due, or to enforce
performance or observance of any obligations, agreements or covenants of the
Authority under the Note, this Agreement, or otherwise.
WMIX
-MISCELLANE, OUS
7.2 Waivers, etc. No failure on the part of the City to exercise and no delay in
exercising, and no course of dealing with respect to, any right under this Agreement, or any other
M
c ® a e
agreement or instrument referred to in this Agreement, shall operate as a waiver thereof, nor shall
any single or partial exercise of any such right preclude any other or further exercise thereof or
the exercise of any other right. The remedies herein and therein provided are cumulative and not
exclusive of any remedies provided by laver.
7.3 Successors etc. This Agreement shall be binding upon and inure to the benefit of
the parties hereto and any subsequent holder of the dotes and its successors and assigns,
7.4 �yernfln a�xr, This Agreement shall be ccaDstrued in accordance with, and
governed by the laws of the State of Oklahoma.
7.5 Amendments, This Agreement may not be amended, modified or waived except
with the written consent of the parties hereto.
7.6 Notices. All requests and notices under the Agreement shall be hand delivered or
sent by United State Mail, postage prepaid, addressed as follows, except that either party may be
written notice change of address, its counsel or its counsel's address for subsequent notices to be
given hereunder:
Authority Owasso public Forks Authority
207 South Cedar
Owasso, Oklahoma 74055
Attention: Denise rode, Chairman
with a cote to:
Donald D. Cates
.Authority Attorney
Suite 680, Park Centre
525 South Main
Tulsa, Oklahoma 74103
City: City of Owasso
207 South Cedar
Owasso, Oklahoma 74055
Attn: Derr se Bode, Mayor
Ronald D. Caws
City Attorney
Suite 680, ParkCentre
525 South Main
Tulsa, Oklahoma 74
7
Notice given hereunder shall be deemed given upon receipt by the principal addressee.
7.8 Severability. If any provision of this Agreement shall be held invalid or
unenforceable by any court of competent jurisdiction, such holding shall not invalidate or render
unenforceable any other provision hereof
1.9 E &ecuiion in urargrp tja. This Agreement may be executed in several
counterparts, each of which shall be an original and all of which shall constitute one and the same
instrument.
ATTEST:
Dy: _ ®e®
Marti �3outwell, Secretary
Owasso Public Works Authority
ley.
Denise Bode, Chairman
"Authority"
City of Owasso, Oklahoma
By:
Denise Bode, Mayor
TO: HONORABLE CHAIR AND TRUSTEES
CL ASS PUBLIC WORKS AUTHORITY
FROM: JARED T. BATES 9, C-�' �g'
CAPITAL PROJECTS ENGINEER
SUIBJECT: CHANGE ORDER NUMBER 1, AT OR RELIEF LINE
DATE: August 16, 200'1
BACKGROUND:
313mz��
Trench Rock — 20 days
Hard limestone rock was encountered from station 900 through station 1700.
The contract boring logs showed only shale, which is generally assumed to be
easily removed.
Boring Rock —14 days
'The boring; at the railroad was especially difficult because half the casing was
in hard limestone and the other half was in soil shale. The drill bit tended to
stay in the soft rock, so it had to be weighed down and the rotation slowed in
order to keep the alignment from being too high.
® Extended dock _. 32 days
Future allowance for unanticipated hard rock.
Garver Engineers recommends approval of the 81 day time extension (see Attachment 3)°
ODE ODEQ has stated they have no problem granting a time extension, The contractor has stated
that no additional payment for changed conditions or future changed conditions will be asked
for if this time extension is granted, therefore, payment for substantial changes in conditions
will not be a future issue.
Change Carder Number 1 is a request for a time extension only. No additional costs will be
incurred by the OPWA in granting the added time. Funds for the project are provided in a loan
fiom the Oklahoma Water Resources Board.
RECOMMENDAMONS:
Staff recommends Trustee approval of Change Order Number 1 for a time extension of 81
calendar days and establishing a completion date of November 14, 2001, to the contract for
construction of the Ator Relief Line with Sapulpa Digging, Inc.
U_a� I
V,
A
OS
RONALD OVENDOL YN
J OCAN I Lj I
0
0 LARKIN BAILEY
awl T 6 F*OUNDA'nON
�
V:
co
VZ
C6 ABANDONED
�K , - ... X\ I I . I \4�' —
'b - ' I ' v� N
0 MANN
(�' )� OLE
48.5' 71/ 0
25'i A\
-TEMP. EASE!
--TEMP. EASE. A'. 60 L.F. OF NG
slu
BORING
6 — C_
L Z=ASR7ING-
)N
8 (9.375' WALL)
5�u 4 --St394q'22'E EXIS 1
1�5+ou S
CORNER SEMION S.,
8 €i 9h S T PiE E T -o'h r;H
_-- ------ -
BORE HOLE
49' TF�
NO. 1-
80 L.F. OF 9 18801' PGF
REMOVE AND 36 STEEL,1 CASING
REPLACE DRIVE (0.375";:w LL)
0%. 2
NCR, '1
,
CD
MAILS END
MAI DEVELOPMENT
I
AND LARKIN LEY'
JANIE DEVELOPMENT
cly,
�EYNOLDS RIDDELL FOUNDA ON
B 60d NAIL I S.r9. SIDE 24
+ I SECTION th MINGO
�E ON SM. +
-0
0
SECTION & 12V OF
ly
LF. 0
I'IC�I ICI ,
99f I LF.
I 188.Do LF
0 8% 1 0 0.18%
.15rALL 18' DU 11L£ IRON RPE R E EXISTING 10' PIPE AA9 INSTALL M' PIPE
10100 121 0 14-00 16
'11100 ri 100 8100 �__UA_RVER EN WEER .-A-1. PUBLIC WORKS AUTHORITY
ATOR SEWER RELIEF LINE
m) N
18f0D 2
SCALE:
W
IP
�ORING & 36t
im.
I
LF.
BORING
&
36'
'4-
nro
ASING (O.375WI1)
CA
IN GTO
375
ALL
4
Ln
0)
U')
0
Lr
cl
u"
o�
Lo
0
>:
>:
�D
z
11
-A
4
4
3>�-
.15rALL 18' DU 11L£ IRON RPE R E EXISTING 10' PIPE AA9 INSTALL M' PIPE
10100 121 0 14-00 16
'11100 ri 100 8100 �__UA_RVER EN WEER .-A-1. PUBLIC WORKS AUTHORITY
ATOR SEWER RELIEF LINE
m) N
18f0D 2
SCALE:
W
b0 0 IV.LUI L
ffl��M
To-
Jay UNike, PE
M.
From'.
Les Gregg
Date.
8/13/01
Re-
Owasso ATOR schedale
Attached fmd revised time schedule for the Owasso ATOR sewed ine pwjeq, the dme delays are
listed below.
We are asking for a time extension oWl tw i 4"—tf- ii
................
. ......... ...
TO/TO'd TS62 TEE OT6 '3NI ON1901a udindus q�.qT TooF,-PT-onu
I
Garver, Inc.
Engineers
5411 S. 125th East Ave.
Suite 301
Tulsa, OK 74146 -6206
918 -250 -5922
FAX 918 -250 -6529
www.garverinc.com
August 13, 2001
P. Robert Carr
City of Owasso
P.O. Box 180
Owasso, Old 74055
Re: Ator Relief Line
Dear Mr. Carr:
RECEIVED
GARVERIENGINEERS
A request from Sapulpa Digging, Inc. for a 81 day calendar time extension is enclosed.
As noted only 49 days at their time extension is based on justifiable delays for rock and utility relocation,
The contractor has, however, encountered limestone rock from station 9 +00 and 17+00 which he could not
have reasonably anticipated. A bore log (131-1 -1) included in the bid documents at Station 14-00 indicates
only clay and shale to a depth of 15 feet. The contractor encountered limestone at 3 feet to the full depth of
the trench ( >12 feet) at this bore hole location at Station 9 +00,
A map showing the limestone rock area and the bore log are attached.
The contractor agreed in writing not to request additional monies for this or any future changed conditions
for the 81 day time extension.
We spoke with Mr. Patrick Rosch of ODEQ concerning the time extension. The consent order date for the
completion of this project is September 1, 2001. Mr. Rosch stated that he agreed the time extension was
justifiable and the consent order could be modified upon receipt of a written request by the City of Owasso
stating the reasons for the extension.
We recommend approval of the 81 day time extension by the City of Owasso.
Sincerely,
ice
Brentwood, TF! - Fayetteville, AR a Huntsville, AL ® Little Rock. AR - Madison. MS - Topeka, KS e Tulsa. OK
REPORT OF TEsT
HOLE Nd.. BH-1
DATE DRILLED: 11-18-00 TICKET NO: 09808
P. 0. NO.: verbal LAB. NO: 110008
11 REPORT TO: Garver Engineers, Inc.
PROJECT: Owasso Ater Relief Line
JOB LOCATION: Owasso, Oklahorna DRILLER: D. Collins
HOLE LOCATION: As shown on drawing
DRILL METHOD: Auger SURFACE ELEVATION:
WATER TABLE: 0.0 ft. DEPTH OF HOLE: 15.0 ft.
0.0-3.5
Clay, 'Fan and gray sh I
(medium firm)
3.5-11.0
Shale, tan
TEST
PENEI -RATION TESTS
(medium firm to firm)
NO.
FROM TO BLOWS
11.15.0 --
0-
Shale, Dark gray
(very firm)
15.0
Terminated
BOTTOM OF HOLE
TEST ATTERBERG LIMITS NATURAL
NO.
LIQUID
PLASTIC
MOISTURE
LIMIT
INDEX
WASH SIEVE
ANALYSIS
TEST
SIEVE %
UNIFIED
SOIL
OSI
NO.
PASSING
SOIL
GROUP
NO.
#200
CLASS
No water was encountered at the time of
—1drilling,
I
CHANGEORDER
PROJECT: Ator Relief Line CHANGE ORDER NUMBER: I
TO CONTRACTOR:
Sapulpa Digging Inc
P.O. Box 1105
Sapulpa, OK 74067
The Contract is changed as follows:
DATE: August 21, 2001
CONTRACT DATE: January 16, 2001
CONTRACT FOR: Sewer Line Upgrade and
Elimination of Lift Station
1 h� c�r� in l time ®f coin le�iox� �✓as 140 day with coin letio x_clat� ®f Au t 2 200. Contract time is
f NovembeL 14,2001. ififre is no change in CQntract
Sum.
Not valid until signed by the Owner and Contractor
The original Contract Sum was $818,270.00
Net change by previously authorized Change Orders $0.00
The Contract Sum prior to this Change Order was $818,270.00
The Contract Sum will be unchanged by this Change Order in the amount of $0.00
The new Contract Sum including this Change Order will be $818,270.00
The Contract Time will be increased by 81 DAYS
The date of Substantial Completion as of the date of this Change
Order therefore is November 14, 2001
Note: This summary does not reflect changes in the Contract Sum which have been authorized by Construction Change Directive.
S 31 l Da D'
a iinn....
CONTRACTOR
P.O. Box 1105, Sapulpa, OK 74067
ADDRESS
Elm
Owasso Public Works Authority
OWNER
P.O. Box 180, Owasso, OK 74405
ADDRESS
M."
DATE DATE
TO:
SUBJECT-
HONORABLE
UIT C
HONG LE CHAIR AND TRUSTEES
O ASSO PUBLIC WORKS AUTHORITY
CHRIS ROBERTS, CHAIR
YARDWASTE REVIEW COMMITTEE
ADOPTION OF YARWASTE ACTION PLAN
August 15, 2001
On April 3, 2001, the OPWA Trustees voted to appoint a committee to analyze the existing yardwaste
program and develop a proposal for managing the yardwaste disposal needs of the community. After
extensive research, a preliminary report was drafted and potential program modifications were presented
at the July 10, 2001 Council work session. A copy of the preliminary report is attached for reference.
The following alternatives were included:
Short -term Wtions
Permanently close the disposal station to public access
® Clean up existing disposal site
Continue curbside collection of residential yardwaste indefinitely
Initiate community outreach program focusing on reduction of yardwaste volume
L® term o bons
® Initiate public /private partnerships for collecting and disposing of yardwaste materials
Purchase an air - curtain burner for waste disposal
On July 12, 2001, the Yardwaste Review Committee conducted a final meeting to further evaluate the
options presented in the preliminary report. Consequently, several of the alternatives previously
considered were opted out and an additional element was introduced. Following a consensus of the
committee, a final proposal was developed.
The proposed action plan includes each of the options listed above, as well as a seasonal clean up event.
Due to time constraints, the committee was unable to thoroughly evaluate the potential long -term
strategies. However, due to their potential value, each has been included in the action plan as a
recommendation for future consideration. Consequently, the proposed action plan consists primarily of
short -term strategies, which should result in immediate improvements to the yardwaste separation
program. The proposed action plan, however, will need to be updated as the community expands and the
corresponding volume of yardwaste increases.
Page 2
`Y"ardwaste Action Plan
Page 3
Yardwaste .Action Flan
Provide seasonal clean—MI events sponsoro the City
Citywide cleanup events will be planned for the spring and fall each year whereby the City of Owasso
will provide a free day at the Quarry Landfill for residential yardwastc disposal. The seasonal cleanup
program should be initiated in the spring of 2002.
Evaluate public /privateartncrshit�s for the collection and disposal of ardwaste materials
Consideration should be given to the benefits of public /private partnerships. Increased financing is the
most obvious benefit, In addition, the private sector brings with it the opportunity and the flexibility of
innovative financing by looking at several options not available to the public sector. Private solid waste
companies may be interested in collecting and disposing of Owasso's residential yardwastc. Another
possibility is to lease the property dedicated as our disposal area to a private company for yardwastc
disposal operations.
9N299mw chasing an air curtain burner for fizturc yardwaste disposal needs n air curtain burner would virtually eliminate yardwastc disposal problems. The air - curtain
centrally located or moved around depending on need. The air-cu in burner enables clean
d bunting and is a disposal technique seldom scrutinized by local fire departments. 1�Tew
st is approximately X30,000,
CONCLUSION:
Prior to implementing proposed modifications, the committee recommends that Owasso residents be
notified of program changes and closure of the disposal station. This can best be accomplished by
advertising in the Owasso Reporter, inserting notices in customer utility bills and posting signage at the
Recycle Center. Each medium should include directions to the Quarry Landfill to provide Owasso
residents an alternate site for disposing of large and bulky yardwastc materials.
C® ATION:
The Yardwaste Review Committee recommends Trustees approval of the Yardwaste Action Plan as
submitted.
1. Memorandum – Alternate Yardwaste Management Alan (dated July 6, 2001)
2. Quote for contractor services – Bill Basore Trucking & Excavation, LLC
3. Quote for contractor services -- R.L. Hensley Construction, Inc.
Im
SUBJECT:
DATE, .
BACKGROUND:
Honorable Chair and Trustees
Owasso Public Works Authority
Yardwaste Review Committee
.ALT EMNATE YARDWASTE MANAGEMENT PLAN
July 6, 2001
On April 3, 2001, the OPWATrustees were asked to consider and adopt a yardwaste management plan,
which specified specific short and long-term modifications to the existing yardwaste separation program.
Operational challenges associated with limited available disposal area, collection equipment reliability
and reduced manpower necessitated the recommended improvements. The following elements were
included in the proposal:
In response to public opposition relative to certain aspects of the proposal, the Trustees voted to appoint a
committee to analyze the existing yardwaste program and develop an alternate plan for managing the
yardwaste disposal needs of the community. The committee was to be comprised of five (5) citizens, one
(1) ®P WA Trustee and one (1) member of staff,
Since curbside collection generates revenue and the drop-off station does not, the committee elected to
analyze each element of the program independently. It was felt that this approach would direct the
committee to a specific area(s) in need of modification. To objectively weigh program benefits against
operating costs, the committee performed a cost/benefit analysis using new data acquired through up-to-
date utility billing records in addition to data included in the original action plan.
Page 2
Yardwaste Review Committee
Curbside Collection Expenses
Costs associated with curbside collection of yardwaste consist of labor, vehicle fuel and equipment
repairs. Average expenses are approximately $1,600 per month. Each of the expense categories are
detailed below:
Labor: Presently, the only labor - related costs are for one (1) seasonal drivers Inmates from the
Oklahoma Department of Corrections are used to supplement collection needs at essentially no
cost for labor. Lased on eight (5) collection days per month at $9.00 per hour, a total of
approximately $600 per month is paid.
Vehicle fuel /repairs- Due to the age of vehicles used in the collection of yardwaste, mechanical
repairs can be anticipated. Based on a history of repairs and fuel consumption, costs of
approximately $1,000 per month are typically incurred.
Rgd Volycarte On the average, 20 new polycarts /month are issued to new yardwaste customers
throughout the collection season. Based on the cost for a new cart at $60 each, a total of $1,200
per month is paid.
dear °Mastic basso dear plastic bags are purchased in bulk quantities to supply yardwaste
customer needs. The cost associated with the bags is approximately $300 /month.
Curbside Collection Revenue
Revenue from curbside yardwaste collection is derived from customers paying for the use of a 90-gallon
container and /or purchasing clear plastic bags. Average monthly revenue is approximately $4,400. Each
revenue source is detailed below:
90:gallon containers: Customers are charged $6,50 per month for a yardwaste container. There
are currently 551 customers utilizing the cart option; therefore, revenue is approximately $3,500
per month. ($6,50 /month x 551 containers = $3,776,50 /month)
Clear,plastic bates°., In lieu of the plastic container, customers may purchase clear plastic bags
For $3,50/10 bags. Revenue collected for these bags, based on the number of bags collected
monthly, is approximately $600 per month. ($0.35/ bag x 1,745 bags /month = $611 o50 /month)
The variance between this cost analysis and the analysis included in the action plan proposed by city staff
is due to a significant increase in the identification of the actual number of customers utilizing the plastic
container system. A recent utility billing audit identified an additional 286 red polycart customers, which
were not previously accounted for,
Page 3
Yardwaste Review Committee
Page 5
Yardwaste Review Committee
Page 6
Yardwaste Review Committee
Purchase an air-curtain burner for waste"
Purchasing an air-curtain burner would virtually eliminate yardwaste disposal problems. The air-curtain
burner can be centrally located or moved around depending on need. The air-curtain burner enables clean
and controlled burning and is a disposal technique seldom scrutinized by local fire departments,
Equipment cost is approximately $309000.
BILL BASORE TP_UC_KING & E <.CFV �TION, LLC
P.O. Be,-,- 1153
Skiatook, OK 74070
Quoted toa
CITY OF' OWASSO
Attna Chris Roberts
F 0. Boas 180
Owasso, OK 74055
M Ml
Quote Number:
01
Subtotal
4,75o.u0
Sales Tax
R`PUM : R L HOGLEY CIDN'STFUCT40(4 fNC
OPOSAL SUBMIT'[ ED TO
aW OF 00,A860
.0. BOX 180
Mr, GrATE andZIF
IINKISSO Dy, 7415'51�
-PROPOSE harebytafuerthsh
the S'-'m CA
BID BELOW
PROPO'SAL
R, L- P-PEN SLEY CONSTRUC TION, INC,
x'81 1 E. 46th, M,
TULS�,A, OKJ-AY40MA MI A6
(918)(363-9936
FAX (91=64-9558
CHRIS ROBERTS tPHC
ROGER STEPPE NS 1W
MA
JUL. 23. 2001 11: 01AM P 1
FHUNE tC. - '319 664 3'5,-58
MO 2/2-495
911 8 272-4999
TREE BURNING
76TI-I ST NORTH C1rV'eAF-Q
ancVabor - compleafs- in accordance
Paymmil to be made as foiiows:
INVOICE UP",)N COMPLETION. PAYMENT' WITHIN 30 CALENDAR DAYS
hofoa 'V'
PAGE 1 OF 1
7,1104ZT: l
PHONE
AM matariul is guarani aed to 13t-,i ou, 5pacified. All wmk to be complolad in a+varkrnunfike
mtmkrmer nomiding to gtej)cjasd practiceu. Any altat,ation ray deviation from bra- Auft ' d A
[mv irN-olvirtg extras costs X41 be 6XCCL1t9d only upnr-. w6 ten orderg, and wilt become an Signvill", & Mn
•y've charge over Una UL! ove the osiimato. All 6greements corilingemupon atxikeg, ac ci- -7)
datum or dm'ays beyond our corwof. Owner w carry fire, tornado and other neceseany Nota; This propmat me be vitthdravin b�,/ u-,,
x's"v ance wm"mm zl a Mely Mvemdby Wrjt'i�ar iorl's Cidmpen.5ohonlnsuranco. it not accepted -qvigiin 21
Ode, t e re by v., tmll W�zAY6 anti
SCOPE <3,1�:WORK MI-ME-S & LiMITED -FC,)-.
WE WILL DIG A BURN PIT AND OURN TREE8 THAT ARE STORED ON aTY PROPERTY
WE WILL PROVIDE THE FOLLOWING FOR HOURLY WORK:
I EA TRACK LOADER W1 OPERATOR ANO FUEL
I EA TRACK 110E W/ OPERATOR AND FUEL
1 EA AIR CURTAIN DESTRUCTOR BURNER W FUEL
EXGLUMO-bui
BURN PERMIT EEE5 BY HEALTH DEPARTMENT ($50,00 / PFQ
kOCEPTANCE OF PROPOSAL -The abov@ prices, specificnflons
ind conditjon8 aye saijsleciwy and tare hereby acrx.�ptad. Yovore authorized signature
do the woik es spe-dified. %ymentwifl be made tis outhed above.
)4ftfe- Of ACCE-Plemcn: sigt)i,klure
A-0